Terms and Conditions

Effective Date: April 13, 2026

These Terms and Conditions (“Terms”) govern your access to and use of the website located at splwaterproofing.com (the ‘Site’) and any services provided by [Your Company Name] (“Company,” “we,” “us,” or “our”). By accessing or using this Site, you agree to be legally bound by these Terms.

1. Eligibility and Use

You must be at least 18 years old to use this Site. You agree to use the Site only for lawful purposes and in compliance with all applicable federal, state, and local laws and regulations.

You agree not to:

  • Use the Site in any way that could damage or impair functionality
  • Attempt unauthorized access to systems or data
  • Submit false, misleading, or fraudulent information

2. No Professional Advice / Informational Use

All content on this Site is provided for general informational purposes only and does not constitute professional, engineering, or construction advice.

Use of this Site does not create a contractor-client relationship. Such a relationship is only formed through a written agreement executed by both parties.

3. Estimates, Proposals, and Scope of Work

Any pricing, estimates, or project descriptions provided via the Site, email, phone, or otherwise are non-binding and subject to change.

A binding agreement exists only when:

  1. A written contract is executed, and
  2. Required deposits (if any) are received

Final project cost may vary due to:

  • Hidden or unforeseen site conditions
  • Structural deficiencies
  • Code compliance requirements
  • Changes in material costs or availability
  • Client-requested scope changes

4. Licensing and Compliance

[Your Company Name] operates in accordance with applicable California contractor laws and regulations. Nothing on this Site shall be interpreted as a guarantee of permit approval, inspection outcome, or regulatory compliance beyond the scope of contracted work.

5. Scheduling, Delays, and Force Majeure

Project timelines are estimates only and are subject to change.

We are not liable for delays caused by circumstances beyond our control, including but not limited to:

  • Weather conditions
  • Material shortages
  • Labor disruptions
  • Site inaccessibility
  • Acts of God

We reserve the right to reschedule work as necessary for safety and operational reasons.

6. Payments and Collections

Payment terms will be defined in your contract or invoice. Failure to make timely payments may result in:

  • Suspension of work
  • Late fees or interest charges
  • Legal action or collections

Client agrees to pay all reasonable costs of collection, including attorney’s fees, where permitted by law.

7. Warranties and Limitations

All warranties are limited to those explicitly stated in a written contract.

Warranty exclusions may include (but are not limited to):

  • Pre-existing conditions not disclosed or visible
  • Structural movement or failure
  • Work performed by third parties
  • Lack of proper maintenance
  • Normal wear and tear

Except as expressly provided, all warranties—express or implied—are disclaimed to the fullest extent permitted by law.

8. Limitation of Liability

To the maximum extent permitted under California law:

  • The Company shall not be liable for any indirect, incidental, special, or consequential damages
  • Total liability for any claim arising out of or relating to the Site or services shall not exceed the amount paid by the client for the specific service giving rise to the claim

This limitation applies regardless of the legal theory (contract, tort, negligence, strict liability, etc.).

9. Indemnification

You agree to indemnify, defend, and hold harmless [Your Company Name], its owners, employees, and affiliates from any claims, damages, liabilities, or expenses arising from:

  • Your misuse of the Site
  • Your violation of these Terms
  • Your violation of any law or third-party rights

10. Intellectual Property

All content on this Site—including text, graphics, logos, images, and layout—is the exclusive property of [Your Company Name] and protected under applicable intellectual property laws.

Unauthorized use, reproduction, or distribution is strictly prohibited.

The Site may contain links to third-party websites or services. We do not control and are not responsible for their content, policies, or practices.

Use of third-party services is at your own risk.

12. Privacy

Your use of this Site is also governed by our Privacy Policy. By using the Site, you consent to the collection and use of information as described therein.

13. Governing Law and Venue

These Terms shall be governed by the laws of the State of California.

Any disputes shall be resolved exclusively in the courts located in [Your County], California.

At the Company’s discretion, disputes may first be submitted to mediation before litigation.

15. Severability

If any provision of these Terms is found to be invalid or unenforceable, the remaining provisions shall remain in full force and effect.

16. Changes to Terms

We reserve the right to modify these Terms at any time. Updates will be posted on this page with a revised effective date.

Continued use of the Site constitutes acceptance of the updated Terms.

17. Contact Information

SPL Water Proofing Inc
2229 Elder Ave
Santa Ana, CA 92704 714-791-5327
contact@splwaterproofing.com

By using this Site, you acknowledge that you have read, understood, and agree to be bound by these Terms and Conditions.